Tender document — White Topping of Selected Roads under GoK Grants, Package-2 (BBMP, Project Central-8)

Comprehensive Development of Selected Roads by Providing
White Topping Under GoK Grants Package - 2 Technical Bid
Tenderer Page 36 of 65 Executive Engineer,
PC-8, BBMP, Bengaluru
Works, are subject to prior Approval by the Employer before their use.
19. Safety
19.1 The Contractor shall be Responsible for the Safety of all Activities on the Site.
20. Discoveries
20.1 Anything of Historical or other Interest or of Significant Value unexpectedly Discovered on
the Site is the Property of the Employer. The Contractor is to notify the Employer of such
Discoveries and carry out the Employer's Instructions for dealing with them.
21. Possession of the Site
21.1 The Employer shall give Possession of all parts of the Site to the Contractor. If Possession of a
Part is not given by the Date stated in the Contract Data, the Employer is deemed to have
delayed the Start of the Relevant Activities and this will be Compensation Event.
22. Access to the Site
22.1 The Contractor shall allow the Employer and any Person authorized by the Employer Access
to the Site, to any Place where Work in connection with the Contract is being carried out or is
intended to be carried out and to any Place where Materials or Plant are being manufactured
/ fabricated / assembled for the Works.
23. Instructions
23.1 The Contractor shall carry out all Instructions of the Employer which comply with the
Applicable Laws where the Site is located.
24. Procedure for Resolution of Disputes
24.1 If the Contractor is not satisfied with the Decision taken by the Employer, the Dispute shall be
referred by either Party to Arbitration within 30 days of the Notification of the Employer’s
Decision.
24.2 If neither Party refers the Dispute to Arbitration within the above 30 days, the Employer’s
Decision will be final and binding.
24.3 The Arbitration shall be conducted in accordance with the Arbitration Procedure stated in
the Special Conditions of Contract.